Effective Date: 5 August 2025
Welcome to RADICAL AEC Solutions. These Terms and Conditions govern your use of our website and services. By accessing our site or working with us, you agree to be bound by the terms stated below.
1. Company Overview
RADICAL AEC Solutions is a design and construction firm offering end-to-end architectural, fabrication, and general contracting services. Our specialties include residential, commercial, institutional, and industrial projects, as well as BIM and AI-enabled solutions for smarter building delivery.
2. Acceptance of Terms
By accessing or using our website or services, you confirm that you have read, understood, and agreed to comply with these Terms and Conditions. If you do not agree, please do not use our website or engage with our services.
3. Services Offered
We provide the following services:
-
Architectural Consultancy and Design
-
Design & Build (Turnkey Projects)
-
General Contracting
-
Project Management Consultancy (PMC)
-
Fabrication and PEB Structures
-
Elevator & Lift Solutions
-
Interior Fit-Outs
-
BIM and AI-enabled Construction Services
All services are subject to formal agreements, scope documentation, and timelines outlined in individual client contracts.
4. Intellectual Property
All content, including but not limited to designs, plans, drawings, text, graphics, images, videos, and company branding found on our website and in our communications are the intellectual property of RADICAL AEC Solutions and protected under applicable copyright and trademark laws.
You may not copy, modify, distribute, publish, or commercially exploit any content without our prior written consent.
5. Client Responsibilities
When engaging with RADICAL AEC Solutions, clients must:
-
Provide accurate and complete information relevant to the project
-
Respond to communication in a timely manner
-
Ensure access to the site (if applicable) and approvals are provided
-
Honor all payment terms as agreed in the formal agreement
Failure to comply may result in delays, additional charges, or service termination.
6. Project Timelines and Delivery
While we strive to meet project deadlines, external factors such as weather conditions, supplier delays, or regulatory approvals may impact timelines. RADICAL AEC Solutions will not be held liable for delays caused by circumstances beyond our control.
7. Payments and Invoicing
All payment terms, milestone-based billing, and taxes (if applicable) are clearly outlined in your contract. Late payments may incur penalties and delay project progress. We reserve the right to suspend or terminate services in the event of non-payment.
8. Warranties and Limitations
RADICAL AEC Solutions provides services with reasonable skill, care, and professionalism. However, we do not warrant that our services will be uninterrupted or error-free.
To the maximum extent permitted by law, RADICAL AEC Solutions disclaims any liability for:
-
Loss of data, revenue, or profit
-
Indirect or consequential damages
-
Delays or disruptions due to third-party vendors or government regulations
9. Termination
We reserve the right to suspend or terminate services or website access without notice if you breach these terms, misuse our content, or violate any applicable laws.
Upon termination, any outstanding dues must be settled immediately.
10. Privacy Policy
Our Privacy Policy outlines how we collect, use, and protect your personal data. By using our website or contacting us, you consent to the collection and handling of information as described in our Privacy Policy.
11. External Links
Our website may contain links to third-party sites. We are not responsible for the content or accuracy of any external websites linked from our site. Visiting them is at your own risk.
12. Governing Law
These Terms and Conditions are governed by the laws of India, and any disputes arising from them shall fall under the jurisdiction of the courts located in Nagpur.
13. Updates to These Terms
RADICAL AEC Solutions reserves the right to update or modify these Terms at any time. We recommend reviewing this page periodically for any changes.
14. Contact Us
For questions, clarifications, or requests related to these Terms and Conditions, you may contact us at:
Email: radicalaecsolutions@gmail.com
Phone: +91 932 642 5960
Office: Fabricators, 221, Mirza Rd, behind Agrasen Metro Station, Khadan, Gandhibagh, Nagpur, Maharashtra 440018
